Publications & Podcasts

Updated AIA Contract Documents; Subcontractor Loss of Productivity Claims

Spring 2017 Alerts and Newsletters

UPDATED AIA CONTRACT DOCUMENTS; SUBCONTRACTOR
LOSS OF PRODUCTIVITY CLAIMS

Every ten years the American Institute of Architects ("AIA") updates its industry-leading family of standard contracts for construction and design. The last set of revisions were issued in 2007. AIA is on schedule to issue updated versions of its standard documents in 2017. The first wave of contract documents will be released in late April with additional documents scheduled for release in the late summer. AIA has indicated that revisions to documents, particularly those applicable to design professionals, shall incorporate "opt-in" provisions for sustainability criteria, such as LEED certification, for many of its standard documents.

Stay tuned for further updates on the evolution of AIA documents. Verrill Dana's Construction Law Group will be planning information sessions in late summer to update owners, contractors and subcontractors on these new developments.

*****

GENERAL CONTRACTOR GETS HIT FOR SUBCONTRACTOR'S LOSS OF PRODUCTIVITY CLAIMS DESPITE "NO DAMAGES FOR DELAY"
PROVISION IN SUBCONTRACT

Suffolk Construction was hit an adverse verdict in connection with a subcontractor's claim for diminished labor productivity. The court awarded the subcontractor approximately $320,000 for its increased labor costs as well as about $471,000 in legal fees incurred by the subcontractor in pursuing its claims.

The subcontractor alleged that the general contractor mismanaged the project and failed to properly coordinate the trade contractors. As a result, subcontractor said it was forced to work in an unproductive, out-of-sequence fashion, and had idle crews when work was unavailable. Suffolk refused the subcontractor's requests for additional time to complete its work and instructed the subcontractor to increase staffing to meet the original completion deadline. The subcontractor increased its manpower, completed its scope of work and then pursued claims for its increased labor costs due to constructive acceleration of the work and diminished productivity of its labor forces. Following a trial, the subcontractor prevailed. The Massachusetts Court of Appeals upheld the trial court's decision.

The general contractor argued that the "no damages for delay" subcontract clause prohibited recovery of money damages associated with delays and limited the subcontractor to an extension of time for completion of its work. The Court rejected Suffolk's argument. First, the Court ruled that Suffolk could not rely on this common subcontract clause since it denied the subcontractor its sole remedy, an extension of time. In addition, the Court determined that the "no damages for delay" clause did not apply because the subcontractor was not seeking damages for "delay", but rather was seeking damages for increased crew size due to the compression of the schedule caused by the general contractor's purported mismanagement. Suffolk unsuccessfully countered that the Court ought to construe the term "delay" as set forth in the subcontract to include damages related to an idle work force.

This case will likely result in owners and prime contractors revising their contracts to specifically exclude claims for increased labor costs, loss of productivity or constructive acceleration claims. Whether or not an explicit contract prohibition on such claims will be upheld in circumstances similar to this case remains to be seen.

___________________________________________________________________
This communication is intended for general information purposes and as a service to clients and friends of Verrill Dana, LLP. This publication, which may be considered advertising under the ethical rules of certain jurisdictions, should not be construed as legal advice or a legal opinion on any specific facts or circumstances, nor does it create attorney-client privilege.

Firm Highlights

Matter

Patent Litigation: Mesenchymal Stem Cells

Represented small biotech company and two academic researchers against large pharmaceutical company in dispute over inventorship of several patents relating to mesenchymal stem cells and their uses, as well as defending against numerous state...

Matter

Patent & Trade Secret Litigation: IT Infrastructure Software

Represented large provider of IT management solutions in lawsuits in U.S. District Courts for the Eastern District of New York and the Northern District of California against competitor alleging infringement of patents relating to...

Publication/Podcast

Domestic Discovery for Foreign Arbitrations? – Now It’s the Supreme Court’s Turn

U.S. Supreme Court building
Matter

Patent Litigation: NPEs

Represented many companies over the years in patent litigations brought by numerous non-practicing entities, including in U.S. District Courts for the Eastern District of Texas, District of Delaware and Northern District of California; aggressively...

Matter

Patent Litigation: MEMS Microphones

Represented large semiconductor manufacturer in an ITC investigation and parallel district court proceeding in U.S. District Court for the Northern District of Illinois, defending against two patents owned by a competitor relating to microelectromechanical...

Publication/Podcast

Finding Teeth in Massachusetts' Prompt Payment Act

In Tocci v. IRIV Partners, LLC, Boston Harbor Industrial Development LLC and Hudson Insurance Co. (November 19, 2020, Sup. Ct. 19-405), the Massachusetts Superior Court granted summary judgment on a contractor’s breach of contract...

News

65 Verrill Attorneys Recognized by Best Lawyers® 2022, Including Eight Named Lawyers of the Year

(August 31, 2021) – 65 Verrill attorneys were recognized as "Best Lawyers" by Best Lawyers® 2022 , including 8 attorneys named “Lawyer of the Year,” a distinguished recognition for only a single lawyer in...

Publication/Podcast

The Massachusetts Supreme Judicial Court Clarifies the Contours of the Attorney-Client Privilege and Work Product Doctrine in Internal Investigations

In Attorney General v. Facebook, Inc. , No. SJC-12496 (March 24, 2021), [i] the Massachusetts Supreme Judicial Court clarified the scope of protection afforded by the attorney-client privilege and the work product doctrine to...

Publication/Podcast

Make Your Own Law with Tom Bean

On March 2, attorney Tom Bean appeared on a Pod617 - The Boston Podcast Network episode, "Make Your Own Law with Tom Bean." He discusses what it takes to get a proposed law on...

Matter

Patent Litigation: Semiconductors

Represented semiconductor manufacturer in patent case against competitor in litigation in U.S. District Court for the District of Delaware, in which both sides asserted patents relating to power management and A-D converters; conducted Markman...

Contact Verrill at (855) 307 0700