Updated AIA Contract Documents; Subcontractor Loss of Productivity Claims

Spring 2017 Alerts and Newsletters

UPDATED AIA CONTRACT DOCUMENTS; SUBCONTRACTOR
LOSS OF PRODUCTIVITY CLAIMS

Every ten years the American Institute of Architects ("AIA") updates its industry-leading family of standard contracts for construction and design. The last set of revisions were issued in 2007. AIA is on schedule to issue updated versions of its standard documents in 2017. The first wave of contract documents will be released in late April with additional documents scheduled for release in the late summer. AIA has indicated that revisions to documents, particularly those applicable to design professionals, shall incorporate "opt-in" provisions for sustainability criteria, such as LEED certification, for many of its standard documents.

Stay tuned for further updates on the evolution of AIA documents. Verrill Dana's Construction Law Group will be planning information sessions in late summer to update owners, contractors and subcontractors on these new developments.

*****

GENERAL CONTRACTOR GETS HIT FOR SUBCONTRACTOR'S LOSS OF PRODUCTIVITY CLAIMS DESPITE "NO DAMAGES FOR DELAY"
PROVISION IN SUBCONTRACT

Suffolk Construction was hit an adverse verdict in connection with a subcontractor's claim for diminished labor productivity. The court awarded the subcontractor approximately $320,000 for its increased labor costs as well as about $471,000 in legal fees incurred by the subcontractor in pursuing its claims.

The subcontractor alleged that the general contractor mismanaged the project and failed to properly coordinate the trade contractors. As a result, subcontractor said it was forced to work in an unproductive, out-of-sequence fashion, and had idle crews when work was unavailable. Suffolk refused the subcontractor's requests for additional time to complete its work and instructed the subcontractor to increase staffing to meet the original completion deadline. The subcontractor increased its manpower, completed its scope of work and then pursued claims for its increased labor costs due to constructive acceleration of the work and diminished productivity of its labor forces. Following a trial, the subcontractor prevailed. The Massachusetts Court of Appeals upheld the trial court's decision.

The general contractor argued that the "no damages for delay" subcontract clause prohibited recovery of money damages associated with delays and limited the subcontractor to an extension of time for completion of its work. The Court rejected Suffolk's argument. First, the Court ruled that Suffolk could not rely on this common subcontract clause since it denied the subcontractor its sole remedy, an extension of time. In addition, the Court determined that the "no damages for delay" clause did not apply because the subcontractor was not seeking damages for "delay", but rather was seeking damages for increased crew size due to the compression of the schedule caused by the general contractor's purported mismanagement. Suffolk unsuccessfully countered that the Court ought to construe the term "delay" as set forth in the subcontract to include damages related to an idle work force.

This case will likely result in owners and prime contractors revising their contracts to specifically exclude claims for increased labor costs, loss of productivity or constructive acceleration claims. Whether or not an explicit contract prohibition on such claims will be upheld in circumstances similar to this case remains to be seen.

___________________________________________________________________
This communication is intended for general information purposes and as a service to clients and friends of Verrill Dana, LLP. This publication, which may be considered advertising under the ethical rules of certain jurisdictions, should not be construed as legal advice or a legal opinion on any specific facts or circumstances, nor does it create attorney-client privilege.

Firm Highlights

Matter

Breach of AIA Construction Contract and Waiver of Consequential Damages By Owner

Our client, a general contractor, and the project owner signed an American Institute of Architect A101 contract with accompanying A201 general conditions. The project included construction of a new office/retail building, and associated site...

News

Getting the Band Back Together: How a Surety Team Can Hit the Right Notes

Construction Exec published an article, "Getting the Band Back Together: How a Surety Team Can Hit the Right Notes," in its November edition, covering the effect COVID-19 has on surety bond producers. Attorney Rob...

Publication/Podcast

Massachusetts COVID-19 Essential Services as they Relate to the Construction Industry

On March 23, 2020, Governor Baker issued “an emergency order requiring all businesses and organizations that do not provide ‘COVID-19 Essential Services’ to close their physical workplaces and facilities to workers, customers and the...

Publication/Podcast

Is the Coronavirus Pandemic a Force Majeure?

Matter

Defense of Breach of Contract, Negligent Construction and Breach of Duty of Workmanship Claims

We successfully defended a large mechanical contractor in connection with lawsuit stemming from the comprehensive failure of the hydronic piping system in a resort hotel's heating and cooling system. Through fact and expert witness...

Matter

Client Recovers on Claim On Differing Site Conditions Claim Involving Subsurface Contaminated Soils

We successfully resolved a substantial claim for our client, a large, Maine based site contractor, stemming from differing site conditions encountered on an aviation facility owned by project federal government. The case stemmed from...

Publication/Podcast

City of Portland Releases Guidelines and Procedures for All Construction Sites and Workers at all Public Works

On Monday, March 30, I participated in a video conference on construction activities and COVID-19 sponsored by the Portland Chamber of Commerce with various City of Portland officials and representatives of the developer/contractor community...

Publication/Podcast

Finding Teeth in Massachusetts' Prompt Payment Act

In Tocci v. IRIV Partners, LLC, Boston Harbor Industrial Development LLC and Hudson Insurance Co. (November 19, 2020, Sup. Ct. 19-405), the Massachusetts Superior Court granted summary judgment on a contractor’s breach of contract...

News

Nearly 80 Verrill Attorneys Recognized by Best Lawyers® 2021, Including a Dozen Named Lawyers of the Year

(August 24, 2020) – Nearly 80 Verrill attorneys were recognized as "Best Lawyers" by Best Lawyers® 2021 , including 12 attorneys named “Lawyer of the Year,” a distinguished recognition for only a single lawyer...

Matter

Procurement

We have assisted many owners, and contractors in design and construction contracting including: Massachusetts Institute of Technology Investment Management Company on over a billion dollars in projects in Kendall Square area of Cambridge, Massachusetts...

Contact Verrill at (855) 307 0700